Revised Code of Washington - RCW Title 18 Businesses And Professions - Section 18.27.010 Definitions

§ 18.27.010. Definitions

The definitions in this section apply throughout this chapter unless the context clearly requires otherwise.

(1) "Contractor" includes any person, firm, corporation, or other entity who or which, in the pursuit of an independent business undertakes to, or offers to undertake, or submits a bid to, construct, alter, repair, add to, subtract from, improve, develop, move, wreck, or demolish any building, highway, road, railroad, excavation or other structure, project, development, or improvement attached to real estate or to do any part thereof including the installation of carpeting or other floor covering, the erection of scaffolding or other structures or works in connection therewith, the installation or repair of roofing or siding, performing tree removal services, or cabinet or similar installation; or, who, to do similar work upon his or her own property, employs members of more than one trade upon a single job or project or under a single building permit except as otherwise provided in this chapter. "Contractor" also includes a consultant acting as a general contractor. "Contractor" also includes any person, firm, corporation, or other entity covered by this subsection, whether or not registered as required under this chapter or who are otherwise required to be registered or licensed by law, who offer to sell their property without occupying or using the structures, projects, developments, or improvements for more than one year from the date the structure, project, development, or improvement was substantially completed or abandoned.

(2) "Department" means the department of labor and industries.

(3) "Director" means the director of the department of labor and industries or designated representative employed by the department.

(4) "Filing" means delivery of a document that is required to be filed with an agency to a place designated by the agency.

(5) "General contractor" means a contractor whose business operations require the use of more than one building trade or craft upon a single job or project or under a single building permit. A general contractor also includes one who superintends, or consults on, in whole or in part, work falling within the definition of a contractor.

(6) "Notice of infraction" means a form used by the department to notify contractors that an infraction under this chapter has been filed against them.

(7) "Partnership" means a business formed under Title 25 RCW.

(8) "Registration cancellation" means a written notice from the department that a contractor's action is in violation of this chapter and that the contractor's registration has been revoked.

(9) "Registration suspension" means either an automatic suspension as provided in this chapter, or a written notice from the department that a contractor's action is a violation of this chapter and that the contractor's registration has been suspended for a specified time, or until the contractor shows evidence of compliance with this chapter.

(10) "Residential homeowner" means an individual person or persons owning or leasing real property:

(a) Upon which one single-family residence is to be built and in which the owner or lessee intends to reside upon completion of any construction; or

(b) Upon which there is a single-family residence to which improvements are to be made and in which the owner or lessee intends to reside upon completion of any construction.

(11) "Service," except as otherwise provided in RCW 18.27.225 and 18.27.370, means posting in the United States mail, properly addressed, postage prepaid, return receipt requested, or personal service. Service by mail is complete upon deposit in the United States mail to the last known address provided to the department.

(12) "Specialty contractor" means a contractor whose operations do not fall within the definition of "general contractor". A specialty contractor may only subcontract work that is incidental to the specialty contractor's work.

(13) "Substantial completion" means the same as "substantial completion of construction" in RCW 4.16.310.

(14) "Unregistered contractor" means a person, firm, corporation, or other entity doing work as a contractor without being registered in compliance with this chapter. "Unregistered contractor" includes contractors whose registration is expired, revoked, or suspended. "Unregistered contractor" does not include a contractor who has maintained a valid bond and the insurance or assigned account required by RCW 18.27.050, and whose registration has lapsed for thirty or fewer days.

(15) "Unsatisfied final judgment" means a judgment or final tax warrant that has not been satisfied either through payment, court approved settlement, discharge in bankruptcy, or assignment under RCW 19.72.070.

(16) "Verification" means the receipt and duplication by the city, town, or county of a contractor registration card that is current on its face, checking the department's contractor registration database, or calling the department to confirm that the contractor is registered.

[2007 c 436 § 1; 2001 c 159 § 1; 1997 c 314 § 2; 1993 c 454 § 2; 1973 1st ex.s. c 153 § 1; 1972 ex.s. c 118 § 1; 1967 c 126 § 5; 1963 c 77 § 1.]

Notes:
     Finding -- 1993 c 454: "The legislature finds that unregistered contractors are a serious threat to the general public and are costing the state millions of dollars each year in lost revenue. To assist in solving this problem, the department of labor and industries and the department of revenue should coordinate and communicate with each other to identify unregistered contractors." [1993 c 454 § 1.]

     Effective date -- 1963 c 77: "This act shall take effect August 1, 1963." [1963 c 77 § 12.]

Sections:  Previous  18.27.005  18.27.010  18.27.020  18.27.030  18.27.040  18.27.050  18.27.060  18.27.065  18.27.070  18.27.075  18.27.080  18.27.090  18.27.100  18.27.102  18.27.104  Next

Last modified: April 7, 2009