41-2617. Contracts for procurement of construction; delay; recovery of damages by contractor
A contract for the procurement of construction shall include a provision which provides for negotiations between the state governmental unit and the contractor for the recovery of damages related to expenses incurred by the contractor for a delay for which the state governmental unit is responsible, which is unreasonable under the circumstances and which was not within the contemplation of the parties to the contract. This section shall not be construed to void any provision in the contract which requires notice of delays, provides for arbitration or other procedure for settlement or provides for liquidated damages.
Section: Previous 41-2607 41-2611 41-2612 41-2613 41-2614 41-2615 41-2616 41-2617 41-2631 41-2632 41-2633 41-2634 41-2635 41-2636 41-2637 NextLast modified: October 13, 2016