Texas Transportation Code § 315.095 Suspension Of Work

Sec. 315.095. SUSPENSION OF WORK. When suit is brought under Section 315.092, the municipality or the contractor may suspend performance of work until a final judgment is rendered in the case and all appellate remedies are exhausted.

Acts 1995, 74th Leg., ch. 165, Sec. 1, eff. Sept. 1, 1995.

Section: Previous  315.066  315.067  315.068  315.069  315.070  315.071  315.072  315.073  315.074  315.075  315.091  315.092  315.093  315.094  315.095

Last modified: September 28, 2016