Revised Code of Washington - RCW Title 60 Liens - Chapter 60.28 Lien For Labor, Materials, Taxes On Public Works

60.28.010 Retained percentage -- Labor and material lien created -- Bond in lieu of retained funds -- Termination before completion -- Chapter deemed exclusive -- Release of ferry contract payments -- Projects of farmers home administration
(1) Contracts for public improvements or work, other than for professional services, by the state, or any county, city, town, district, board, or other public ...

60.28.011 Retained percentage -- Labor and material lien created -- Bond in lieu of retained funds -- Termination before completion -- Chapter deemed exclusive -- Release of ferry contract payments -- Projects of farmers home administration -- General contractor/construction manager procedure -- Definitions
(1) Public improvement contracts shall provide, and public bodies shall reserve, a contract retainage not to exceed five percent of the moneys earned by the ...

60.28.015 Recovery from retained percentage -- Written notice to contractor of materials furnished
Every person, firm, or corporation furnishing materials, supplies, or equipment to be used in the construction, performance, carrying on, prosecution, or doing of any work ...

60.28.020 Excess over lien claims to contractor
After the expiration of the thirty day period, and after receipt of the department of revenue's certificate, and the public body is satisfied that the ...

60.28.021 Excess over lien claims paid to contractor
After the expiration of the forty-five day period for giving notice of lien provided in RCW 60.28.011(2), and after receipt of the department of revenue's ...

60.28.030 Foreclosure of lien -- Limitation of action -- Release of funds
Any person, firm, or corporation filing a claim against the reserve fund shall have four months from the time of the filing thereof in which ...

60.28.040 Tax liens -- Priority of liens
The amount of all taxes, increases and penalties due or to become due under Title 82 RCW, from a contractor or the contractor's successors or ...

60.28.050 Duties of disbursing officer upon final acceptance of contract
Upon final acceptance of a contract, the state, county or other municipal officer charged with the duty of disbursing or authorizing disbursement or payment of ...

60.28.051 Duties of disbursing officer upon completion of contract
Upon completion of a contract, the state, county, or other municipal officer charged with the duty of disbursing or authorizing disbursement or payment of such ...

60.28.060 Duties of disbursing officer upon final acceptance of contract -- Payments to department of revenue
If within thirty days after receipt of notice by the department of revenue of the completion of the contract, the amount of all taxes, increases ...

60.28.080 Delay due to litigation -- Change order or force account directive -- Costs -- Arbitration -- Termination
(1) If any delay in issuance of notice to proceed or in construction following an award of any public construction contract is primarily caused by ...

60.28.900 Severability -- 1955 c 236
If any section, provision or part of this chapter shall be adjudged to be invalid or unconstitutional, such adjudication shall not affect the validity of ...